[{"data":1,"prerenderedAt":513},["ShallowReactive",2],{"document-extended-date-for-performance-D158":3},{"document":4,"label":20,"preview":11,"thumb":21,"description":5,"descriptionCustom":6,"apiDescription":5,"pages":8,"extension":10,"parents":22,"breadcrumb":26,"related":34,"customDescModule":173,"customdescription":6,"mdFm":174,"mdProseHtml":512},{"description":5,"descriptionCustom":6,"label":7,"pages":8,"size":9,"extension":10,"preview":11,"thumb":12,"svgFrame":13,"seoMetadata":14,"parents":15,"keywords":19},"EXTENDED DATE FOR PERFORMANCE This Extended Date for Performance Agreement (the \"Agreement\") is made and effective this [Date], BETWEEN: [YOUR COMPANY NAME] (the \"First party\"), a corporation organized and existing under the laws of the [State/Province] of [STATE/PROVINCE], with its head office located at: [YOUR COMPLETE ADDRESS] AND: [SECOND PARTY] (the \"Second party\"), a corporation organized and existing under the laws of the [State/Province] of [STATE/PROVINCE] of [State/PROVINCE], with its head office located at: [ADDRESS] In consideration of the mutual covenants contained in this agreement, the parties agree as follows: ",null,"Extended Date for Performance","1",29,"doc","https://templates.business-in-a-box.com/imgs/1000px/extended-date-for-performance-D158.png","https://templates.business-in-a-box.com/imgs/250px/158.png","https://templates.business-in-a-box.com/svgs/docviewerWebApp1.html?v6#158.xml",{"title":6,"description":6},[16],{"label":17,"url":18},"Consultant & Contractors","/templates/consulting-contractor-business/","extended date for performance","Extended Date for Performance Template","https://templates.business-in-a-box.com/imgs/400px/158.png",[23,16],{"label":24,"url":25},"Templates","/templates/",[27,28,31],{"label":24,"url":25},{"label":29,"url":30},"Legal Agreements","/templates/business-legal-agreements/",{"label":32,"url":33},"Terms & Warranties","/templates/terms-and-warranties/",[35,39,43,47,51,55,59,63,67,71,75,79,83,98,112,125,138,155],{"label":36,"url":37,"thumb":38,"extension":10},"Performance Evaluation","/template/performance-evaluation-D694","https://templates.business-in-a-box.com/imgs/250px/694.png",{"label":40,"url":41,"thumb":42,"extension":10},"How to Review Employee Performance","/template/how-to-review-employee-performance-D12595","https://templates.business-in-a-box.com/imgs/250px/12595.png",{"label":44,"url":45,"thumb":46,"extension":10},"Performance Agreement","/template/performance-agreement-D14026","https://templates.business-in-a-box.com/imgs/250px/14026.png",{"label":48,"url":49,"thumb":50,"extension":10},"Checklist Giving Job Performance Feedback","/template/checklist-giving-job-performance-feedback-D686","https://templates.business-in-a-box.com/imgs/250px/686.png",{"label":52,"url":53,"thumb":54,"extension":10},"Performance Based Contract","/template/performance-based-contract-D12702","https://templates.business-in-a-box.com/imgs/250px/12702.png",{"label":56,"url":57,"thumb":58,"extension":10},"Worksheet_Evaluating Management Performance","/template/worksheet_evaluating-management-performance-D135","https://templates.business-in-a-box.com/imgs/250px/135.png",{"label":60,"url":61,"thumb":62,"extension":10},"We Have Extended our Business Hours","/template/we-have-extended-our-business-hours-D1454","https://templates.business-in-a-box.com/imgs/250px/1454.png",{"label":64,"url":65,"thumb":66,"extension":10},"Demand for Extension of Payment Date","/template/demand-for-extension-of-payment-date-D444","https://templates.business-in-a-box.com/imgs/250px/444.png",{"label":68,"url":69,"thumb":70,"extension":10},"Board Resolution Establishing Performance Committee","/template/board-resolution-establishing-performance-committee-D58","https://templates.business-in-a-box.com/imgs/250px/58.png",{"label":72,"url":73,"thumb":74,"extension":10},"How to Create a Performance Improvement Plan","/template/how-to-create-a-performance-improvement-plan-D12564","https://templates.business-in-a-box.com/imgs/250px/12564.png",{"label":76,"url":77,"thumb":78,"extension":10},"Letter_Purchase Order Issued on Acceptance of Delivery Date","/template/letter_purchase-order-issued-on-acceptance-of-delivery-date-D1408","https://templates.business-in-a-box.com/imgs/250px/1408.png",{"label":80,"url":81,"thumb":82,"extension":10},"Employee Appraisal Form","/template/employee-appraisal-form-D688","https://templates.business-in-a-box.com/imgs/250px/688.png",{"description":84,"descriptionCustom":6,"label":85,"pages":86,"size":87,"extension":10,"preview":88,"thumb":89,"svgFrame":90,"seoMetadata":91,"parents":93,"keywords":92,"url":97},"AMENDMENT AGREEMENT This Amendment Agreement (\"Agreement\") is entered into effect as of [DATE], BETWEEN: [FIRST PARTY NAME], (\"First Party\"), an individual with their main address located at OR a corporation organized and existing under the laws of the [State/Province] of [STATE/PROVINCE], with its head office located at: [COMPLETE ADDRESS] AND: [SECOND PARTY NAME], (\"Second Party\") an individual with their main address located at OR a corporation organized and existing under the laws of the [State/Province] of [STATE/PROVINCE], with its head office located at: [COMPLETE ADDRESS] WHEREAS, the Parties entered into the Original Agreement, which they now wish to amend; AND WHEREAS, the Parties mutually desire to amend the Original Agreement on the terms and conditions set forth in this Amendment; NOW, THEREFORE, in consideration of the mutual covenants and agreements contained herein, and intending to be legally bound, the Parties agree to amend the Original Agreement as follows: AMENDMENTS TO THE ORIGINAL AGREEMENT Modification of Terms: Clause [NUMBER] of the Original Agreement is hereby amended to read as follows: [NEW AMENDED LANGUAGE, PROVIDING A CLEAR AND DETAILED DESCRIPTION OF THE AMENDMENTS, INCLUDING ANY CHANGED RESPONSIBILITIES, TIMELINES, FINANCIAL TERMS, OR OTHER SIGNIFICANT ASPECTS]. Addition of Terms: The following new clause is added to the Original Agreement as Clause [NUMBER]: [DETAILED DESCRIPTION OF THE NEW CLAUSE, INCLUDING ITS SCOPE, APPLICATION, AND HOW IT INTEGRATES WITH THE EXISTING CLAUSES].","Amendment Agreement","2",513,"https://templates.business-in-a-box.com/imgs/1000px/amendment-agreement-D13872.png","https://templates.business-in-a-box.com/imgs/250px/13872.png","https://templates.business-in-a-box.com/svgs/docviewerWebApp1.html?v6#13872.xml",{"title":92,"description":6},"amendment agreement",[94,96],{"label":29,"url":95},"business-legal-agreements",{"label":29,"url":95},"/template/amendment-agreement-D13872",{"description":99,"descriptionCustom":6,"label":100,"pages":101,"size":87,"extension":10,"preview":102,"thumb":103,"svgFrame":104,"seoMetadata":105,"parents":107,"keywords":110,"url":111},"[DATE] [CONTACT NAME] [ADDRESS] [ADDRESS 2] [CITY, STATE/PROVINCE] [ZIP/POSTAL CODE] SUBJECT: LETTER OF INTENT-ACQUISITION OF BUSINESS Dear [CONTACT NAME]: This letter (\"Letter of Intent\") sets forth the basic preliminary terms between the Buyer or his nominee and yourselves regarding the purchase of the [SPECIFY] business (the \"Business\") carried on by yourselves. Except as specifically set forth herein, this Letter of Intent shall not constitute an agreement between the parties and no agreement shall be deemed to exist until execution of a definitive purchase agreement. It is proposed that Buyer will acquire certain assets of the Business which Buyer believes to be necessary to the future of the Business, including the warehouse in [CITY/STATE] in which [COMPANY NAME] the Company has invested [AMOUNT] in cash and which has been financed by a mortgage loan of approximately [AMOUNT] granted by the [SPECIFY COMPANY] [CITY/STATE]. Buyer understands that the said warehouse has no other charges or liabilities affecting it other than the said mortgage loan. Buyer may either purchase the warehouse outright or enter into a lease-purchase or instalment transfer of ownership which is satisfactory to both parties. The gross purchase price for the said warehouse will be [AMOUNT]. Buyer may purchase or lease barrels and other equipment currently owned by the Company which are necessary to operate the Business, on a cash or instalment basis agreeable to both parties. The specific assets to be purchased and the amounts to be paid by Buyer in connection with this transaction remain to be negotiated by the parties. This Letter of Intent also evidences the intentions of the parties with respect to the following agreements: Buyer will enter into a [NUMBER]-year employment agreement with [COMPANY NAME], providing for the Company will be responsible for the purchase of [SPECIFY] for Buyer. The agreement will contain the customary terms and conditions found in employment agreements in similar transactions and will provide for the usual non-competition and non-solicitation covenants to be entered into by the Company in favour of Buyer. It is expressly understood that if the contemplated transaction is consummated, the aggregate amount of commission paid or payable to yourselves (net of reasonable expenses acceptable to Buyer) in respect of all purchases of [SPECIFY] made through you from the date of this Letter of Intent to the date of closing, with the exception of commissions earned on the [NUMBER] truckloads of [SPECIFY] to be delivered to Buyer during the week of [DATE] to [DATE], will be applied against remuneration payable to the Company in the first year of his employment agreement. If the contemplated transaction is not consummated, all such commissions paid or payable will be treated as commissions. Buyer will enter into a [NUMBER]-year employment agreement with [EMPLOYEE NAME], providing for the payment of a gross base salary of [ANNUAL SALARY] per year, to be paid weekly, subject to annual review. [EMPLOYEE NAME] will be President of the Business and the employment agreement will provide for health benefits, automobile, expenses and bonus arrangements","Letter of Intent_Acquisition of Business","3","https://templates.business-in-a-box.com/imgs/1000px/letter-of-intent_acquisition-of-business-D5197.png","https://templates.business-in-a-box.com/imgs/250px/5197.png","https://templates.business-in-a-box.com/svgs/docviewerWebApp1.html?v6#5197.xml",{"title":106,"description":6},"letter of intent_acquisition of business",[108,109],{"label":29,"url":95},{"label":29,"url":95},"letter intent_acquisition business","/template/letter-of-intent_acquisition-of-business-D5197",{"description":113,"descriptionCustom":6,"label":114,"pages":115,"size":87,"extension":10,"preview":116,"thumb":117,"svgFrame":118,"seoMetadata":119,"parents":121,"keywords":120,"url":124},"SERVICE AGREEMENT This SERVICE AGREEMENT (\"Agreement\") is effective [DATE], BETWEEN: [COMPANY NAME] (the \"Contractor\"), a company organized and existing under the laws of [STATE/PROVINCE], with its head office located at: [COMPLETE ADDRESS] AND: [COMPANY NAME] (the \"Customer\"), a company organized and existing under the laws of [STATE/PROVINCE], with its head office located at: [COMPLETE ADDRESS] (The Contractor and the Customer shall be individually referred to as a \"Party\" and collectively referred to as the \"Parties\", as the context may require). WHEREAS A. Contractor has experience and expertise in [DESCRIBE EXPERIENCE AND SERVICE]. B. Customer desires to have Contractor provide services for them. C. Contractor desires to provide services to Customer on the terms and conditions set forth herein (the \"Services\"). NOW THEREFORE, in consideration of the above recitals, the representations, warranties, and agreements contained in this Agreement and for other good and valuable consideration, the receipt and adequacy of which are now acknowledged, the Parties agree as follows: SERVICES PROVIDED Beginning on upon agreement to this contract, [CONTRACTOR] will provide to [CUSTOMER] the following service (collectively, the /Services\"): Description of the project: [DESCRIBE THE SERVICE REQUIRED]. SCOPE OF WORK Contractor agrees to provide Services pursuant to the Scope of Work set forth in Exhibit A attached hereto (the \"Scope of Work\"). TERM Unless both parties mutually agree on an extension, this contract will automatically terminate on [SPECIFY]. PERFORMANCE The parties agree to do everything possible to ensure that the terms of this Agreement take effect. PAYMENT FOR SERVICES In exchange for the Services rendered, a payment of [SPECIFY] will be made to the Contractor upon completion of the scheduled Services described in this Contract. If an invoice is not paid on the due date, interest will be added to the current balance. These amounts shall be payable, and the Customer shall pay all overdue amounts at the lesser of [SPECIFY] per cent per annum or the maximum percentage permitted by applicable law. Or Customer will pay Contractor as follows: [SPECIFY]. DELIVERY OF SERVICES The Contractor will exercise due diligence in the provision of services. However, the Customer acknowledges that the indicated delivery times and other payment milestones listed in Scope of Work are estimates and do not constitute final delivery dates. SECURITY The Contractor must make reasonable security arrangement to protect Material from unauthorized access, collection, use, alteration or disposal. OWNERSHIP RIGHT The Customer shall hold the copyright for the agreed version of the Services as delivered, and the Customer's copyright notice may be displayed in the final version. All works, ideas, discoveries, inventions, patents, products or other information that may be protected by copyright (collectively, the \"Work Product\" developed in whole or in part by the Contractor in connection with the Services, shall be the exclusive property of the Customer. Upon request, the Contractor shall execute all documents necessary to confirm or perfect the exclusive ownership of the Customer's \"Work Product\". The Contractor retains exclusive rights to pre-existing materials used in the Customer's projects. The Customer shall not have the right to reuse, resell or otherwise transfer material belonging to the contractor or third parties. The Contractor reserves the right to use the finished public product as an example of a product. RETURN OF PROPERTY Upon the expiry or termination of this Agreement, the Contractor will return to the Customer any property, documentation, records or Confidential Information which is the property of the Customer. COMPENSATION For all services rendered by the Contractor under this Agreement, the Customer shall indemnify the Contractor. In the event that the Customer fails to make any of the payments mentioned, the Contractor shall have the right, but shall not be obliged, to exercise any of the following remedies: ","Service Agreement","6","https://templates.business-in-a-box.com/imgs/1000px/service-agreement-D12711.png","https://templates.business-in-a-box.com/imgs/250px/12711.png","https://templates.business-in-a-box.com/svgs/docviewerWebApp1.html?v6#12711.xml",{"title":120,"description":6},"service agreement",[122,123],{"label":29,"url":95},{"label":29,"url":95},"/template/service-agreement-D12711",{"description":126,"descriptionCustom":6,"label":127,"pages":115,"size":128,"extension":10,"preview":129,"thumb":130,"svgFrame":131,"seoMetadata":132,"parents":133,"keywords":136,"url":137},"INDEPENDENT CONTRACTOR AGREEMENT This Independent Contractor Agreement (\"Agreement\") is made and effective [Date], BETWEEN: [INDEPENDENT CONTRACTOR NAME] (the \"Independent Contractor\"), a company organized and existing under the laws of the [State/Province] of [STATE/PROVINCE], with its head office located at: [COMPLETE ADDRESS] AND: [YOUR COMPANY NAME] (the \"Company\"), a company organized and existing under the laws of the [State/Province] of [STATE/PROVINCE], with its head office located at: [YOUR COMPLETE ADDRESS] RECITALS Independent Contractor is engaged in providing [Describe] business services, its Employer Tax I.D. Number is [Insert], and its Business License Number is [insert]. Independent Contractor has complied with all Federal, State, and local laws regarding business permits, sales permits, licenses, reporting requirements, tax withholding requirements, and other legal requirements of any kind that may be required to carry out said business and the Scope of Work which is to be performed as an Independent Contractor pursuant to this Agreement. Independent Contractor is or remains open to conducting similar tasks or activities for clients other than the Company and holds themselves out to the public to be a separate business entity. Company desires to engage and contract for the services of the Independent Contractor to perform certain tasks as set forth below. Independent Contractor desires to enter into this Agreement and perform as an independent contractor for the company and is willing to do so on the terms and conditions set forth below. NOW, THEREFORE, in consideration of the above recitals and the mutual promises and conditions contained in this Agreement, the Parties agree as follows: TERMS This Agreement shall be effective commencing [Date], and shall continue until terminated at the completion of the Scope of Work which shall occur no later than [Date] or by either party as otherwise provided herein. STATUS OF INDEPENDENT CONTRACTOR This Agreement does not constitute a hiring by either party. It is the parties intentions that Independent Contractor shall have an independent contractor status and not be an employee for any purposes, including, but not limited to, [laws]. Independent Contractor shall retain sole and absolute discretion in the manner and means of carrying out their activities and responsibilities under this Agreement. This Agreement shall not be considered or construed to be a partnership or joint venture, and the Company shall not be liable for any obligations incurred by Independent Contractor unless specifically authorized in writing. Independent Contractor shall not act as an agent of the Company, ostensibly or otherwise, nor bind the Company in any manner, unless specifically authorized to do so in writing. TASKS, DUTIES, AND SCOPE OF WORK Independent Contractor agrees to devote as much time, attention, and energy as necessary to complete or achieve the following: [Describe]. The above to be referred to in this Agreement as the \"Scope of Work\". It is expected that the Scope of Work will completed by [Date]. Independent Contractor shall additionally perform any and all tasks and duties associated with the Scope of Work set forth above, including but not limited to, work being performed already or related change orders. Independent Contractor shall not be entitled to engage in any activities which are not expressly set forth by this Agreement. The books and records related to the Scope of Work set forth in this Agreement shall be maintained by the Independent Contractor at the Independent Contractor's principal place of business and open to inspection by Company during regular working hours. Documents to which Company will be entitled to inspect include, but are not limited to, any and all contract documents, change orders/purchase orders and work authorized by Independent Contractor or Company on existing or potential projects related to this Agreement. Independent Contractor shall be responsible to the management and directors of Company, but Independent Contractor will not be required to follow or establish a regular or daily work schedule. Supply all necessary equipment, materials and supplies. Independent Contractor will not rely on the equipment or offices of Company for completion of tasks and duties set forth pursuant to this Agreement. Any advice given Independent Contractors regarding the scope of work shall be considered a suggestion only, not an instruction. Company retains the right to inspect, stop, or alter the work of Independent Contractor to assure its conformity with this Agreement. ASSURANCE OF SERVICES Independent Contractor will assure that the following individuals (the \"Key Employees\") will be available to perform, and will perform, the Services hereunder until they are completed (identify by title and name as applicable): [Name of Key Employee, Title] [Name of Key Employee, Title] The Key Employees may be changed only with the prior written approval of the Company, which approval shall not be unreasonably withheld. COMPENSATION Independent Contractor shall be entitled to compensation for performing those tasks and duties related to the Scope of Work as follows: [Describe] Such compensation shall become due and payable to Independent Contractor in the following time, place, and manner: [Describe] NOTICE CONCERNING WITHHOLDING OF TAXES Independent Contractor recognizes and understands that it will receive a [specify tax] statement and related tax statements, and will be required to file corporate and/or individual tax returns and to pay taxes in accordance with all provisions of applicable Federal and State law. Independent Contractor hereby promises and agrees to indemnify the Company for any damages or expenses, including attorney's fees, and legal expenses, incurred by the Company as a result of independent contractor's failure to make such required payments. AGREEMENT TO WAIVE RIGHTS TO BENEFITS Independent Contractor hereby waives and foregoes the right to receive any benefits given by Company to its regular employees, including, but not limited to, health benefits, vacation and sick leave benefits, profit sharing plans, etc. This waiver is applicable to all non-salary benefits which might otherwise be found to accrue to the Independent Contractor by virtue of their services to Company, and is effective for the entire duration of Independent Contractor's agreement with Company. This waiver is effective independently of Independent Contractor's employment status as adjudged for taxation purposes or for any other purpose. Neither this Agreement, nor any duties or obligations under this Agreement may be assigned by either party without the consent of the other. TERMINATION This Agreement may be terminated prior to the completion or achievement of the Scope of Work by either party giving [number] days written notice. Such termination shall not prejudice any other remedy to which the terminating party may be entitled, either by law, in equity, or under this Agreement. NON-DISCLOSURE OF TRADE SECRETS, CUSTOMER LISTS AND OTHER PROPRIETARY INFORMATION Independent Contractor agrees not to disclose or communicate, in any manner, either during or after Independent Contractor's agreement with Company, information about Company, its operations, clientele, or any other information, that relate to the business of Company including, but not limited to, the names of its customers, its marketing strategies, operations, or any other information of any kind which would be deemed confidential, a trade secret, a customer list, or other form of proprietary information of Company. Independent Contractor acknowledges that the above information is material and confidential and that it affects the profitability of Company. ","Independent Contractor Agreement",62,"https://templates.business-in-a-box.com/imgs/1000px/independent-contractor-agreement-D160.png","https://templates.business-in-a-box.com/imgs/250px/160.png","https://templates.business-in-a-box.com/svgs/docviewerWebApp1.html?v6#160.xml",{"title":6,"description":6},[134],{"label":17,"url":135},"consulting-contractor-business","independent contractor agreement","/template/independent-contractor-agreement-D160",{"description":139,"descriptionCustom":6,"label":140,"pages":8,"size":141,"extension":10,"preview":142,"thumb":143,"svgFrame":144,"seoMetadata":145,"parents":146,"keywords":153,"url":154},"COMPANY NAME:_______________________ Address: _______________________________________ City: ______________________________ State/Province: ___________ Zip/postal code__________ Country: ________________ Phone: _________________ Fax: __________________ Email: _________________________________________ Purchase Order The following number must appear on all related correspondence, shipping papers, and invoices: P.O. NUMBER: Contact: Address: _______________________________________ City: ______________________________ State/Province: ___________ Zip/postal code___________ Country: ________________ Phone: _________________ Fax: __________________ Email: _________________________________________ Ship To:","Purchase Order",49,"https://templates.business-in-a-box.com/imgs/1000px/purchase-order-D1411.png","https://templates.business-in-a-box.com/imgs/250px/1411.png","https://templates.business-in-a-box.com/svgs/docviewerWebApp1.html?v6#1411.xml",{"title":6,"description":6},[147,150],{"label":148,"url":149},"Sales & Marketing","sales-marketing",{"label":151,"url":152},"Bids & Quotes","bids-quotes","purchase order","/template/purchase-order-D1411",{"description":156,"descriptionCustom":6,"label":157,"pages":8,"size":87,"extension":10,"preview":158,"thumb":159,"svgFrame":160,"seoMetadata":161,"parents":163,"keywords":171,"url":172},"[DATE] [CONTACT NAME] [ADDRESS] [ADDRESS 2] [CITY, STATE/PROVINCE] [ZIP/POSTAL CODE] SUBJECT: NOTICE OF DEFAULT Dear [Contact name], Please be advised that the undersigned is the holder of a certain promissory note made by you dated [Date], in the original principal amount of [Amount]. You are hereby notified that you have defaulted under said note because you have failed to pay the installment due [Date], in the amount of [Amount]","Notice of Default in Payment","https://templates.business-in-a-box.com/imgs/1000px/notice-of-default-in-payment-D391.png","https://templates.business-in-a-box.com/imgs/250px/391.png","https://templates.business-in-a-box.com/svgs/docviewerWebApp1.html?v6#391.xml",{"title":162,"description":6},"notice of default in payment",[164,167,170],{"label":165,"url":166},"Finance & Accounting","finance-accounting",{"label":168,"url":169},"Business Loans","business-loan",{"label":165,"url":166},"notice default in payment","/template/notice-of-default-in-payment-D391",false,{"seo":175,"reviewer":188,"quick_facts":192,"at_a_glance":195,"personas":199,"variants":224,"glossary":252,"clauses":286,"how_to_fill":337,"common_mistakes":368,"faqs":393,"industries":421,"comparisons":438,"diy_vs_lawyer":455,"jurisdictions":468,"related_template_ids_curated":489,"schema":500,"classification":501},{"meta_title":176,"meta_description":177,"primary_keyword":178,"secondary_keywords":179},"Extended Date for Performance Template | Free Word Download","Free extended date for performance template to formally extend a contract deadline. Edit in Word, export as PDF.","extended date for performance template",[180,181,182,183,184,185,186,187],"contract extension agreement template","extension of time to perform contract","deadline extension letter template","contract performance extension word","extension of contract deadline template free","agreement to extend performance date","time extension agreement template","notice of extension of performance date",{"name":189,"credential":190,"reviewed_date":191},"Bruno Goulet","CEO, Business in a Box","2026-05-02",{"difficulty":193,"legal_review_recommended":194,"signature_required":194},"medium",true,{"what_it_is":196,"when_you_need_it":197,"whats_inside":198},"An Extended Date for Performance is a legally binding amendment that formally postpones a contractual obligation's deadline to a new agreed date. This free Word download lets you document the extension in writing, preserving the original contract's terms while replacing the old performance date with a new one that both parties sign off on.\n","Use it whenever a party to an existing contract cannot meet an original deadline — due to supply chain delays, unforeseen circumstances, regulatory holdups, or mutual re-scheduling — and both sides agree to move the performance date forward. It prevents the non-performing party from being in default and protects the other party's right to enforce the new date.\n","The document identifies the original contract and deadline, states the new extended performance date, confirms all other terms remain in force, and includes signature blocks for both parties. It also typically addresses whether the extension affects any related milestones, payment schedules, or penalty clauses tied to the original date.\n",[200,204,208,212,216,220],{"title":201,"use_case":202,"icon_asset_id":203},"Small business owners","Extending a supplier or vendor delivery deadline without voiding the contract","persona-small-business-owner",{"title":205,"use_case":206,"icon_asset_id":207},"Real estate professionals","Pushing back a closing date on a purchase and sale agreement","persona-real-estate-agent",{"title":209,"use_case":210,"icon_asset_id":211},"Construction project managers","Formally extending a contractor's completion date due to material delays","persona-project-manager",{"title":213,"use_case":214,"icon_asset_id":215},"Startup founders","Granting a partner or vendor additional time to meet a product delivery milestone","persona-startup-founder",{"title":217,"use_case":218,"icon_asset_id":219},"Procurement officers","Documenting an agreed deadline shift on a purchase order or service contract","persona-procurement-officer",{"title":221,"use_case":222,"icon_asset_id":223},"Legal and operations managers","Amending multiple contract deadlines across a portfolio without drafting full new agreements","persona-operations-director",[225,229,233,237,241,245,248],{"situation":226,"recommended_template":227,"slug":228},"Extending a real estate closing date","Real Estate Contract Addendum","assignment-of-real-estate-contract-D1158",{"situation":230,"recommended_template":231,"slug":232},"Granting more time on a construction milestone","Construction Contract Amendment","amendment-to-sales-contract-D1224",{"situation":234,"recommended_template":235,"slug":236},"Rescheduling a service delivery date in a service agreement","Service Agreement Amendment","amendment-agreement-D13872",{"situation":238,"recommended_template":239,"slug":240},"Extending a loan repayment date","Loan Extension Agreement","secured-lumpsum-promissory-note-agreement-D13041",{"situation":242,"recommended_template":243,"slug":244},"Postponing a product delivery in a purchase order","Purchase Order Amendment","purchase-order-D1411",{"situation":246,"recommended_template":247,"slug":232},"Extending multiple dates across a complex contract","Contract Amendment Agreement",{"situation":249,"recommended_template":250,"slug":251},"Temporarily suspending all performance obligations","Contract Suspension Agreement","license-agreement-contract-of-license-right-to-customer-D1023",[253,256,259,262,265,268,271,274,277,280,283],{"term":254,"definition":255},"Performance Date","The specific calendar date by which a contractual obligation must be fulfilled — delivery, payment, completion, or another defined act.",{"term":257,"definition":258},"Amendment","A written modification to an existing contract that changes one or more of its terms while leaving the rest of the agreement in force.",{"term":260,"definition":261},"Default","A party's failure to fulfill a contractual obligation by its due date, which typically entitles the other party to remedies such as damages or contract termination.",{"term":263,"definition":264},"Time is of the Essence","A contractual clause stating that deadlines are strict and material — missing one constitutes a breach, not merely a technical oversight.",{"term":266,"definition":267},"Consideration","Something of value exchanged between parties to make a contract or amendment legally binding — for an extension, this is often the mutual benefit of avoiding default and litigation.",{"term":269,"definition":270},"Material Breach","A failure to perform a core obligation that is significant enough to excuse the other party from their own obligations and entitle them to sue for damages.",{"term":272,"definition":273},"Force Majeure","A contractual clause excusing a party from performance when extraordinary events outside their control — natural disasters, pandemics, government actions — make performance impossible.",{"term":275,"definition":276},"Addendum","A document added to an existing contract to introduce new terms; unlike an amendment, it supplements rather than replaces original provisions.",{"term":278,"definition":279},"Waiver","The voluntary relinquishment of a known contractual right — for example, a party choosing not to enforce a missed deadline, which can inadvertently set a precedent if not documented.",{"term":281,"definition":282},"Novation","The replacement of one contract or party with a new one, extinguishing the original obligation entirely — distinct from an extension, which preserves the original contract.",{"term":284,"definition":285},"Executed Agreement","A contract or amendment that has been signed by all parties, making it legally effective and binding.",[287,292,297,302,307,312,317,322,327,332],{"name":288,"plain_english":289,"sample_language":290,"common_mistake":291},"Recitals and identification of original contract","Names both parties, identifies the original contract by title and date, and states the specific obligation or deadline being extended.","This Extended Date for Performance Agreement ('Amendment') is entered into as of [DATE] between [PARTY A LEGAL NAME] ('Party A') and [PARTY B LEGAL NAME] ('Party B'), with reference to the [ORIGINAL CONTRACT TITLE] dated [ORIGINAL CONTRACT DATE] ('Agreement').","Referencing the contract by informal name or approximate date rather than the exact title and execution date. This creates ambiguity about which agreement is being amended and can complicate enforcement.",{"name":293,"plain_english":294,"sample_language":295,"common_mistake":296},"Description of original performance obligation","Quotes or summarizes the specific clause in the original contract that established the deadline being extended, so the amendment is anchored to a particular provision.","Section [X] of the Agreement requires [PARTY B] to [DESCRIBE OBLIGATION] no later than [ORIGINAL DATE] ('Original Performance Date').","Describing the obligation in general terms rather than citing the specific contract section. If the original contract is ever disputed, a vague reference makes it harder to prove exactly what was extended.",{"name":298,"plain_english":299,"sample_language":300,"common_mistake":301},"New extended performance date","States the new deadline clearly — as a specific calendar date, not a relative timeframe — replacing the original performance date.","The parties hereby agree that the Original Performance Date of [ORIGINAL DATE] is extended to [NEW DATE] ('Extended Performance Date'). Time remains of the essence with respect to the Extended Performance Date.","Writing the new date as 'an additional 30 days' rather than a fixed calendar date. Relative dates cause disputes when parties disagree on when the clock started.",{"name":303,"plain_english":304,"sample_language":305,"common_mistake":306},"Consideration and mutual agreement","Confirms that both parties are agreeing to the extension voluntarily and identifies the consideration exchanged — typically the mutual benefit of avoiding default and preserving the contract.","In consideration of the mutual covenants set forth herein, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the parties agree to the terms of this Amendment.","Omitting any consideration language when an extension is granted unilaterally. Without documented consideration, the amendment may be unenforceable in jurisdictions requiring it for contract modifications.",{"name":308,"plain_english":309,"sample_language":310,"common_mistake":311},"Effect on related milestones and payment schedules","Addresses whether the extension shifts any downstream milestones, progress payments, or deliverable dates that were tied to the original performance date.","The extension of the Original Performance Date shall [also extend / not affect] the following related milestones: [LIST MILESTONES AND NEW DATES]. All payment obligations under Section [X] remain unchanged unless expressly modified herein.","Extending the primary deadline without addressing linked milestones or payment dates. This creates an internal inconsistency in the contract that parties later dispute.",{"name":313,"plain_english":314,"sample_language":315,"common_mistake":316},"Preservation of original contract terms","Confirms that all terms of the original contract not expressly modified by this amendment remain in full force and effect.","Except as expressly modified by this Amendment, all terms, conditions, and provisions of the Agreement shall remain in full force and effect and are hereby ratified and confirmed. In the event of any conflict between this Amendment and the Agreement, the terms of this Amendment shall govern.","Failing to include a conflict resolution clause. If the amendment and the original contract are inconsistent on any point, courts need a clear rule for which document controls.",{"name":318,"plain_english":319,"sample_language":320,"common_mistake":321},"No waiver of rights","Clarifies that granting this extension does not waive either party's right to enforce the new deadline or any other contract term — preventing the extension from being used as evidence of a pattern of non-enforcement.","The granting of this extension shall not be construed as a waiver of any right or remedy available to either party under the Agreement or applicable law, including the right to enforce the Extended Performance Date strictly.","Omitting a no-waiver clause. A party that has extended a deadline once may find it harder to enforce future deadlines strictly if there is no documented statement that the extension was a one-time accommodation.",{"name":323,"plain_english":324,"sample_language":325,"common_mistake":326},"Representations and warranties","Each party represents that they have authority to enter into this amendment and that no other approvals are needed — important when parties are companies rather than individuals.","Each party represents and warrants that (a) it has full legal authority to execute this Amendment; (b) the person signing has been duly authorized to do so; and (c) this Amendment constitutes a valid and binding obligation enforceable against it in accordance with its terms.","Skipping representations for a 'simple' extension. Corporate parties require authorized signatories — if an unauthorized person signs the amendment, the extension may be void and the original deadline remains in force.",{"name":328,"plain_english":329,"sample_language":330,"common_mistake":331},"Governing law and dispute resolution","States which jurisdiction's law governs the amendment and how disputes will be handled, consistent with the original contract's governing law clause.","This Amendment shall be governed by and construed in accordance with the laws of [STATE / PROVINCE / COUNTRY], consistent with the governing law provisions of the Agreement. Any dispute arising out of this Amendment shall be resolved in accordance with the dispute resolution provisions of the Agreement.","Specifying a different governing law than the original contract. Mismatched governing law clauses create litigation over which set of rules applies before the merits of any dispute are even addressed.",{"name":333,"plain_english":334,"sample_language":335,"common_mistake":336},"Signatures and execution","Provides signature blocks for authorized representatives of both parties, with printed name, title, and date — confirming execution and making the amendment effective.","IN WITNESS WHEREOF, the parties have executed this Amendment as of the date first written above. [PARTY A LEGAL NAME] By: _______________ Name: [NAME] Title: [TITLE] Date: [DATE] [PARTY B LEGAL NAME] By: _______________ Name: [NAME] Title: [TITLE] Date: [DATE]","Having only one party sign the amendment. An extension signed by only one side is not a mutual agreement and will not reliably override the original deadline in a dispute.",[338,343,348,353,358,363],{"step":339,"title":340,"description":341,"tip":342},1,"Identify the original contract and obligation precisely","Locate the exact title, execution date, and section number of the clause establishing the deadline you need to extend. Write these into the recitals block verbatim.","Pull the original contract and copy the clause language directly — do not paraphrase. Exact citation eliminates later disputes about what was extended.",{"step":344,"title":345,"description":346,"tip":347},2,"Enter the new performance date as a fixed calendar date","Calculate the new deadline and enter it as a specific date — e.g., June 30, 2026 — not as 'an additional 30 days from signing.' Both parties should confirm this date in writing before the document is drafted.","If the extension is conditional on an event (e.g., permit approval), add a fallback fixed date so the extension does not become open-ended.",{"step":349,"title":350,"description":351,"tip":352},3,"Review all related milestones and payment dates","Check the original contract for any milestone, payment trigger, or deliverable tied to the performance date being extended. Decide whether each should shift proportionally and document the decision explicitly in the amendment.","A simple table listing each affected milestone, the original date, and the new date is clearer than prose and easier to reference in a dispute.",{"step":354,"title":355,"description":356,"tip":357},4,"Confirm the consideration language","Ensure the amendment includes mutual consideration — typically the parties' acknowledgment that avoiding default and preserving the contract benefits both sides. If one party is receiving additional benefit (e.g., a fee waiver), document it here.","In jurisdictions requiring fresh consideration for contract modifications (several US states), a nominal payment or documented mutual benefit strengthens enforceability.",{"step":359,"title":360,"description":361,"tip":362},5,"Match governing law to the original contract","Copy the governing law clause from the original contract into this amendment. If the original specifies arbitration or a particular court, reference those dispute-resolution provisions here too.","Do not change governing law in an amendment unless you have legal advice confirming both parties' consent and the practical implications.",{"step":364,"title":365,"description":366,"tip":367},6,"Obtain authorized signatures from both parties before the original deadline","Circulate the amendment for signature well before the original performance date expires. An extension signed after the deadline has already passed is more complex to enforce and may be treated as a new agreement rather than an amendment.","Use a timestamped eSign platform so both execution date and identity are documented — critical if the extension is ever challenged.",[369,373,377,381,385,389],{"mistake":370,"why_it_matters":371,"fix":372},"Signing the amendment after the original deadline has passed","Once the original deadline expires, the non-performing party is technically in default. An amendment executed after that point may be characterized as a new agreement rather than an extension, creating complications around consideration and waiver.","Circulate the extension for signatures at least several business days before the original performance date. If the deadline has already passed, consult a lawyer about whether a retroactive amendment or a new agreement is more appropriate.",{"mistake":374,"why_it_matters":375,"fix":376},"Using a relative timeframe instead of a fixed calendar date","Phrases like 'an additional 30 days' create disputes when parties disagree on the start date — was it the original deadline, the date of the amendment, or the date of signing?","Always state the new performance date as a specific calendar date. Both parties should confirm the exact date by email before the amendment is drafted.",{"mistake":378,"why_it_matters":379,"fix":380},"Failing to address linked milestones and payment schedules","Extending a primary deadline without adjusting downstream milestones creates internal contract inconsistencies — a party can be in compliance with the extended date but in breach of a linked payment or deliverable.","Review every milestone, payment trigger, and deliverable in the original contract before finalizing the amendment. Document which dates shift and which stay the same.",{"mistake":382,"why_it_matters":383,"fix":384},"Omitting the no-waiver clause","A party that grants an extension once without a no-waiver clause may find it harder to enforce the new deadline strictly, since the other side can argue a pattern of flexibility has been established.","Include explicit language stating the extension is a one-time accommodation and does not waive any rights under the original contract or applicable law.",{"mistake":386,"why_it_matters":387,"fix":388},"Getting only one signature","A unilateral extension letter is not a binding amendment — it is only one party's expression of willingness. Without both signatures, the non-performing party has no enforceable protection against a default claim.","Treat the extension as a full contract amendment requiring authorized signatures from both parties before it becomes effective.",{"mistake":390,"why_it_matters":391,"fix":392},"Mismatching governing law with the original contract","Different governing law in the amendment creates a threshold dispute about which law applies before the merits of any disagreement are even reached, multiplying litigation cost and complexity.","Copy the governing law clause from the original contract directly into the amendment, and reference the original dispute-resolution mechanism rather than creating a new one.",[394,397,400,403,406,409,412,415,418],{"question":395,"answer":396},"What is an extended date for performance?","An extended date for performance is a written amendment to an existing contract that formally replaces the original deadline for a contractual obligation with a new, later date agreed to by both parties. It preserves all other terms of the original contract and prevents the non-performing party from being in default during the extended period. It is sometimes called a contract extension agreement or an extension of time to perform.\n",{"question":398,"answer":399},"When should I use an extended date for performance agreement?","Use it whenever a party to a contract cannot meet an original deadline and both parties agree to move it. Common triggers include supply chain delays, construction holdups, regulatory approvals taking longer than expected, or mutual commercial re-scheduling. It is appropriate for any type of contract — service agreements, purchase orders, real estate closings, loan repayments, and construction contracts all commonly use this document.\n",{"question":401,"answer":402},"Is a verbal agreement to extend a deadline legally enforceable?","In some jurisdictions, verbal amendments to written contracts may be enforceable if both parties can prove the agreement and the consideration. However, most commercial contracts include an 'entire agreement' or 'amendments in writing' clause that requires any modification to be in writing and signed. Even without such a clause, a written extension is far easier to enforce and eliminates disputes about what was actually agreed.\n",{"question":404,"answer":405},"Does an extension of the performance date require consideration?","In most common-law jurisdictions — including the US and Canada — a contract modification technically requires fresh consideration to be enforceable. For most performance date extensions, the mutual benefit of avoiding default, preserving the contract relationship, and eliminating litigation risk is treated as sufficient consideration by courts. However, in states that follow a stricter view of the pre-existing duty rule, documenting a nominal additional benefit strengthens enforceability.\n",{"question":407,"answer":408},"What happens if the contract contains a 'time is of the essence' clause?","A 'time is of the essence' clause makes deadlines strict and material, meaning missing one is a breach — not merely a technical violation. If your original contract includes this clause, the extended date agreement should explicitly state that time remains of the essence with respect to the new deadline. Courts have generally held that parties can waive a time-is-of-the-essence clause by mutual agreement in writing, but the new deadline will be equally strict.\n",{"question":410,"answer":411},"Does extending a deadline affect other terms in the original contract?","Only if the amendment expressly modifies them or if other obligations are directly tied to the performance date being extended. All other terms — pricing, warranties, confidentiality, governing law — remain in force as written in the original contract. This is why the amendment should always include a clause confirming that unmodified terms are ratified and preserved.\n",{"question":413,"answer":414},"Can I extend a deadline after it has already passed?","Technically yes, but executing an extension after the deadline has passed is significantly more complex. Once the original date expires, the non-performing party is in default, and the other party may have accrued rights — to damages, termination, or both. A post-deadline extension may be characterized as a new agreement rather than an amendment and requires clear documentation of any waiver of accrued remedies. Legal advice is recommended before executing a retroactive extension.\n",{"question":416,"answer":417},"Does this document replace the original contract?","No. An extended date for performance is an amendment — it modifies one or more specific terms of the original contract while leaving everything else intact. The original contract remains the governing document; the amendment changes only the provisions it expressly addresses. Both documents should be kept together and read as a single integrated agreement.\n",{"question":419,"answer":420},"Do both parties need to sign the extension agreement?","Yes. An extension signed by only one party is not a binding mutual amendment — it is a unilateral offer at best. Both authorized representatives must sign before the amendment is effective. If one party is a corporation, the signatory must have actual or apparent authority to bind the entity, which is why the representations and authority clause is critical.\n",[422,426,430,434],{"industry":423,"icon_asset_id":424,"specifics":425},"Construction","industry-construction","Contractor completion dates are routinely extended due to weather, material shortages, or subcontractor delays — written extensions prevent liquidated damages from accruing under the original date.",{"industry":427,"icon_asset_id":428,"specifics":429},"Real estate","industry-real-estate","Purchase and sale closing dates frequently need extension due to financing contingencies, title issues, or inspection delays — an executed extension protects both buyer and seller from default.",{"industry":431,"icon_asset_id":432,"specifics":433},"Professional services","industry-professional-services","Deliverable deadlines in consulting, software development, and creative services contracts are extended when scope changes or client feedback cycles push timelines — the extension documents the agreed new date and protects the service provider.",{"industry":435,"icon_asset_id":436,"specifics":437},"Manufacturing and supply chain","industry-manufacturing","Purchase orders and supply agreements are amended when production delays or logistics disruptions push delivery dates — a formal extension preserves pricing and avoids cancellation and re-procurement costs.",[439,443,447,451],{"vs":440,"vs_template_id":441,"summary":442},"Contract amendment agreement","amendment-agreement-D12688","A general contract amendment can modify any term of the original agreement — price, scope, parties, or timeline. An extended date for performance is a narrowly focused amendment that changes only the deadline for a specific obligation. Use the general amendment when multiple terms need to change; use this document when only a deadline needs to move.",{"vs":444,"vs_template_id":445,"summary":446},"Force majeure notice","D{FORCE_MAJEURE_NOTICE_ID}","A force majeure notice invokes a contractual clause to excuse performance entirely due to extraordinary circumstances outside a party's control — it does not require the other party's consent. An extended date for performance requires mutual agreement and sets a new enforceable deadline. Use force majeure when performance is truly impossible; use an extension when performance is possible but delayed.",{"vs":448,"vs_template_id":449,"summary":450},"Contract termination agreement","D{CONTRACT_TERMINATION_ID}","A termination agreement ends the contract entirely, releasing both parties from further obligations. An extended date for performance preserves the contract and simply moves the deadline. Use termination when both parties agree the relationship or project should not continue; use an extension when both sides want the original deal to proceed on a revised timeline.",{"vs":452,"vs_template_id":453,"summary":454},"Letter of intent","letter-of-intent-D12743","A letter of intent expresses a party's intention to enter into a future agreement — it is typically non-binding and prospective. An extended date for performance is a binding amendment to an already-executed contract. If the original contract has not yet been finalized, a letter of intent may be more appropriate; once a contract is signed, only a formal amendment can change its terms.",{"use_template":456,"template_plus_review":460,"custom_drafted":464},{"best_for":457,"cost":458,"time":459},"Standard commercial deadline extensions where both parties agree and the contract is straightforward","Free","15–30 minutes",{"best_for":461,"cost":462,"time":463},"Extensions involving liquidated damages, time-is-of-the-essence clauses, or linked milestone adjustments","$150–$400 for a one-hour attorney review","1–2 business days",{"best_for":465,"cost":466,"time":467},"High-value contracts, real estate transactions, construction disputes, or extensions executed after the original deadline has passed","$500–$2,000+","3–7 business days",[469,474,479,484],{"code":470,"name":471,"flag_asset_id":472,"note":473},"us","United States","flag-us","Contract modification rules vary by state. Most states follow the common-law pre-existing duty rule, which requires fresh consideration for a modification to be enforceable — though courts broadly recognize mutual benefit as sufficient. Article 2 of the UCC (for goods contracts) permits modifications without fresh consideration if made in good faith. California, New York, and Texas each have nuances; confirm the governing law before executing.",{"code":475,"name":476,"flag_asset_id":477,"note":478},"ca","Canada","flag-ca","Canadian contract law generally requires consideration for a modification to be binding under common law. However, practical courts often find sufficient consideration in the mutual benefit of avoiding litigation. Quebec's civil law framework (Civil Code of Quebec) is more flexible — amendments are generally enforceable when both parties consent in writing. Federal and provincial construction lien regimes may impose mandatory timelines that a private extension cannot override.",{"code":480,"name":481,"flag_asset_id":482,"note":483},"uk","United Kingdom","flag-uk","English contract law traditionally requires consideration for a variation to be binding, though courts have shown increasing willingness to uphold written variations supported by practical benefit (following Williams v Roffey Bros). The Contracts (Rights of Third Parties) Act 1999 may be relevant where third parties have rights under the original contract. Construction contracts under the Housing Grants, Construction and Regeneration Act 1996 have specific adjudication and payment notice requirements that extensions cannot override.",{"code":485,"name":486,"flag_asset_id":487,"note":488},"eu","European Union","flag-eu","Civil law jurisdictions across the EU — France, Germany, Spain, the Netherlands — generally permit contract modifications by mutual consent without requiring fresh consideration, provided consent is documented in writing. GDPR considerations apply if the original contract involves personal data processing and the extension changes the processing timeline. Public procurement contracts in the EU are subject to strict rules on amendments under Directive 2014/24/EU — private extension agreements cannot be used to materially alter public tenders.",[236,490,491,492,244,493,494,495,496,497,498,499],"letter-of-intent_acquisition-of-business-D5197","service-agreement-D12711","independent-contractor-agreement-D160","notice-of-default-in-payment-D391","termination-agreement-D13787","construction-agreement-D13002","real-estate-purchase-agreement-D13234","mutual-release-D1043","demand-letter-D13262","non-disclosure-agreement-nda-D12692",{"emit_how_to":194,"emit_defined_term":194},{"primary_folder":95,"secondary_folder":502,"document_type":503,"industry":504,"business_stage":505,"tags":506,"confidence":511},"terms-and-warranties","agreement","general","all-stages",[507,508,509,510],"legal","contract-amendment","performance-extension","deadline-modification",0.92,"\u003Ch2>What is an Extended Date for Performance?\u003C/h2>\n\u003Cp>An \u003Cstrong>Extended Date for Performance\u003C/strong> is a legally binding amendment to an existing contract that formally replaces a contractual deadline with a new, mutually agreed date. Rather than voiding or replacing the original agreement, it preserves every other term in place while substituting the new performance date for the one the parties can no longer meet. The document identifies the original contract by name and execution date, quotes or cites the specific obligation being extended, states the new deadline as a fixed calendar date, and is executed by authorized representatives of both parties before — or ideally well before — the original deadline expires.\u003C/p>\n\u003Ch2>Why You Need This Document\u003C/h2>\n\u003Cp>Without a written extension, a party that misses a contract deadline is in default — regardless of whether the other side verbally agreed to wait. That default entitles the non-defaulting party to pursue remedies including damages, contract termination, and in some cases liquidated damages penalties. A handshake agreement to extend a deadline offers no protection when the commercial relationship later sours: memories differ, emails are incomplete, and courts require clear evidence of mutual consent to enforce a modification. This template gives both parties a signed, dated record of the new deadline and the terms under which it was granted — eliminating ambiguity, preserving the underlying deal, and protecting both sides if the extended deadline is ever disputed.\u003C/p>\n",1779480683120]